Terms & Conditions

By accessing or using the website, services, or any offerings provided by Gradmarc AdTech LLP (“we”, “us”, “our”), you agree to be bound by these Terms & Conditions. If you do not agree with any part of these terms, you must not use our website or services.

1. Services

We provide a range of technology and digital services, including but not limited to:

• Website Design & Development
• Mobile application development
• Custom software solution and MVP development
• AI automation solutions and workflow optimization
• SEO, search growth support, video editing, and related digital solutions

All services are delivered based on the scope, timelines, deliverables, and pricing mutually agreed upon in writing (via proposal, contract, email confirmation, or statement of work).

2. Intellectual Property

All designs, code, content, visuals, documentation, frameworks, templates, and materials created or provided by Gradmarc AdTech LLP remain our intellectual property unless explicitly transferred in writing.

Clients are granted a non-exclusive, non-transferable license to use the final deliverables solely for the purpose agreed in the project agreement, subject to full payment.

3. Client Responsibilities

You agree to:

• Provide accurate, complete, and timely project requirements, content, assets, feedback, and approvals
• Ensure all materials provided do not infringe any third-party rights
• Use our deliverables in a lawful manner and in compliance with applicable laws

Delays in providing required inputs, content, or approvals may result in timeline extensions, additional costs, or project suspension without liability to us.

4. Payments & Invoices

• All payments must be made according to the agreed milestones or payment schedule
• Late payments may result in suspension of work, delay in delivery, or additional charges
• All quoted prices are exclusive of applicable taxes, duties, or government levies unless explicitly stated otherwise
• Once paid, fees are generally non-refundable except as expressly agreed in writing or required by law

5. Limitation of Liability

To the maximum extent permitted by law, Gradmarc AdTech LLP shall not be liable for:

• Indirect, incidental, special, consequential, or punitive damages
• Loss of profits, revenue, data, goodwill, or business opportunities
• Any downtime, errors, or issues caused by third-party services, hosting providers, APIs, plugins, or platforms outside our direct control

Our total liability shall not exceed the total amount paid by you for the specific service giving rise to the claim.

6. Termination

Either party may terminate the engagement by providing written notice as per the terms agreed in the project agreement.

Upon termination:

• You must pay all outstanding dues for work completed up to the termination date
• We will deliver any completed work product subject to full payment

7. Governing Law & Jurisdiction

These Terms & Conditions are governed by the laws of India.

Any disputes arising out of or in connection with these terms shall be subject to the exclusive jurisdiction of the courts located in Jabalpur, Madhya Pradesh, India, unless otherwise mutually agreed in writing.

8. Changes to Terms

We may update these Terms & Conditions from time to time. Continued use of our website or services after such changes constitutes acceptance of the updated terms.

Contact: For any questions regarding these Terms & Conditions, please reach out to us at contact@gradmarc.com.